Terms & Conditions

🤝 1. Acceptance of Terms

By accessing and using The Home Design Pvt. Ltd. services, you accept and agree to be bound by the terms and provision of this agreement. These terms apply to all visitors, users, and others who access or use our architectural and interior design services.

🏗️ 2. Services Description

The Home Design Pvt. Ltd. provides professional architectural and interior design services including but not limited to:

• 🏠 Residential architecture and design
• 🎨 Interior design and space planning
• 📐 3D visualization and rendering
• 📊 Project management and consultation
• 🌱 Sustainable design solutions

👤 3. Client Responsibilities

Clients are responsible for:

• 📝 Providing accurate project information and requirements
• 💰 Timely payment of fees as agreed
• 📋 Obtaining necessary permits and approvals
• 🔑 Providing site access when required
• 💬 Communicating changes or concerns promptly

💳 4. Payment Terms

Payment terms are established in individual project agreements. Generally:

• ⏰ Initial consultation fees are due upon booking
• 📈 Project fees are typically paid in installments based on project milestones
• ➕ Additional work outside the original scope may incur extra charges
• ⚠️ Late payments may be subject to interest charges

🎨 5. Intellectual Property

All designs, drawings, specifications, and other creative work produced by The Home Design Pvt. Ltd. remain our intellectual property until full payment is received. Upon full payment, clients receive usage rights for the intended project purpose.

⏱️ 6. Project Timeline

Project timelines are estimates based on project complexity and client responsiveness. Delays may occur due to:

• 🔄 Client-requested changes or revisions
• 📋 Permit approval processes
• 🏗️ Site conditions or access issues
• 🌪️ Force majeure events

⚖️ 7. Limitation of Liability

The Home Design Pvt. Ltd. liability is limited to the fees paid for services. We are not responsible for:

• 🔨 Construction defects or contractor performance
• 📋 Permit approval delays or rejections
• 💸 Cost overruns in construction
• 👥 Third-party actions or decisions

❌ 8. Cancellation Policy

Project cancellations must be provided in writing. Cancellation terms:

• 📊 Work completed to date will be billed at agreed rates
• 💰 Refunds are provided for unused portions of advance payments
• 📋 Cancellation fees may apply based on project stage

🔒 9. Privacy & Confidentiality

We respect client privacy and maintain strict confidentiality of project information. Our privacy practices include:

• 🔐 Secure storage of all project documents and client information
• 🤐 Non-disclosure of project details without written consent
• 📋 Compliance with data protection laws and regulations

📝 10. Modifications

The Home Design Pvt. Ltd. reserves the right to modify these terms at any time. Updated terms will be posted on our website and communicated to active clients.

⚖️ 11. Governing Law

These terms are governed by the laws of India. Any disputes will be resolved through binding arbitration or in the courts of competent jurisdiction.